Local Government Lawyer Home Page


Sharpe Edge Webpage Banner

Welcome to Sharpe Edge, Sharpe Pritchard’s local government legal hub on Local Government Lawyer.

Sharpe Edge features news, views and analysis from our team of specialist local government lawyers working at the heart of the latest legal developments. Sharpe Edge platform is also the only place where local government lawyers can get e-access to two law books by our Head of Local Government Rob Hann: The Guide to Local Authority Charging and Trading Powers (‘LACAT’) and The Guide to Local Authority Companies and Partnerships (‘LACAP’).

 

                                                                                                  

Slide background

Liquidated damages and termination

<a href=Clare Mendelle, Francesca Gallagher and James Goldthorpe provide an outline of the Supreme Court's recent decision in Triple Point Technology vs PTT Public Company Limited.

On 16 July 2021, the Supreme Court handed down its long-awaited judgment in the case of Triple Point Technology vs PTT Public Company Limited[1]. This important decision for the construction industry has confirmed the accepted position that while liquidated damages (LDs) cease to accrue on termination any accrued rights to LDs survive termination.

As a reminder, LDs are a pre-determined level of damages to which one party is entitled in the event of certain specified breaches occurring. In the context of construction contracts, LDs clauses are frequently used to incentivise the contractor to complete on time, providing for a fixed rate to be paid to the employer for each day or week that works are late.

Background

In 2013, Triple Point (the Contractor) and PTT entered into a contract (the Contract) under which Triple Point was to provide software and software implementation services to PTT. The works were divided into two Phases, and Triple Point was to be paid in instalments on completion of nine separate milestones.

The Contract included an LDs clause which provided:

“If Contractor [Triple Point] fails to deliver work within the time specified and the delay has not been introduced by PTT, the Contractor shall be liable to pay the penalty at the rate of 0.1% of undelivered work per day of delay from the due date for delivery up to the date PTT accepts such work…” (emphasis added).

Works proceeded slowly and Phase 1 was completed 21 weeks late. PTT accepted these works and paid Triple Point for Phase 1, but refused to pay invoices in relation to Phase 2 as the relevant milestones had not been reached. Subsequently, in May 2014, Triple Point suspended work on the basis of non-payment and left the site. PTT said this was wrongful termination (a repudiatory breach) and so terminated the Contract in March 2015.

Proceedings and Decisions

First Instance[2]

Triple Point commenced proceedings in the Technology and Construction Court claiming payment on unpaid invoices. PTT counterclaimed for LDs for delays up to the point of termination as well as for its other losses arising from the termination.

Triple Point’s claim was dismissed. PTT was awarded its costs of termination as well as LDs for delays incurred prior to termination, on the basis that the LDs provision applied to both Phases 1 and 2 up to the point of termination.

Court of Appeal[3]

Triple Point appealed and PTT cross appealed. The Court of Appeal, relying on a House of Lords judgment[4], decided that the phrase “up to the date PTT accepts such work” meant that the clause did not apply in circumstances where Triple Point did not complete – and so PTT could not accept – the works. As such, the court found that while PTT was entitled to LDs in respect of the completed Phase 1 works, it was not entitled to LDs for the Phase 2 works which had not been completed or accepted.

The Supreme Court

PTT then appealed to the Supreme Court. The main issue it needed to consider was whether LDs were payable in respect of works which were not completed or accepted prior to termination. Lady Arden, who delivered the lead judgment, found that the Court of Appeal’s approach was “inconsistent with commercial reality and the accepted function of liquidated damages” which is to provide a “predictable and certain” remedy. If the right to accrued LDs is simply lost in the event of termination, this overturns the accepted position that accrued rights and liabilities survive termination.

In respect of the language of the clause, it was held that the parties had included the words “up to the date of acceptance” out of caution, to remove any question that LDs were payable after acceptance, but that this was not a pre-condition of Triple Point’s liability. Accordingly, the Supreme Court ruled that PTT was entitled to LDs for any delay that had accrued up to the date of termination, whether or not that work had been completed.

Comment

LDs are a standard feature of construction contracts, conferring predictability and certainty to both employer and contractor. As noted by Lord Leggatt, the approach taken by the Court of Appeal could have created a perverse incentive for a contractor in delay to not complete works in order to avoid liability for LDs. As such, the Supreme Court’s decision is a welcome restatement of the general law that LDs cease to accrue on termination, that thereafter general damages apply, and that the accrued rights and liabilities of parties – including in respect of LDs – survive termination.

As well as providing clarity on this issue, this case serves as a further reminder that contractual clauses should always be drafted in plain language that makes the intention and application of the clauses clear, because if a clause is contested then interpretation is key.

This article is for general awareness only and does not constitute legal or professional advice. The law may have changed since this page was first published. If you would like further advice and assistance in relation to any issue raised in this article, please contact us by telephone or email This email address is being protected from spambots. You need JavaScript enabled to view it.

Clare Mendelle is a Professional Support Lawyer, Francesca Gallagher is a Paralegal and James Goldthorpe is a Paralegal at Sharpe Pritchard LLP.


For further insight and resources on local government legal issues from Sharpe Pritchard, please visit the SharpeEdge page by clicking on the banner below.

sharpe edge 600x100

This article is for general awareness only and does not constitute legal or professional advice. The law may have changed since this page was first published. If you would like further advice and assistance in relation to any issue raised in this article, please contact us by telephone or email This email address is being protected from spambots. You need JavaScript enabled to view it.

LACAT BookFREE download!

A Guide to Local Authority Charging and Trading Powers

Written and edited by Sharpe Pritchard’s Head of Local Government, Rob Hann,

A Guide to Local Authority Charging and Trading Powers covers:

• Updated charging powers compendium          • Commercial trading options

• Teckal ‘public to public’                                    • Localism Act

FREE DOWNLOAD

LACAT BookAvailable to buy:

A Guide to Local Authority Companies and Partnerships

An invaluable, comprehensive toolkit for lawyers, law firms and others advising
on or participating in Local Authority Companies and Partnerships”

- Local Authority Chief Executive

BUY NOW

  More Articles

<a href=

Environment Act 2021: What Does it Mean for Waste Authorities?

Sally Stock, Juli Lau, Ellen Painter and Beth Edwards discuss notable changes made to the Environment Bill 2021-2022, which received Royal Assent on the 9th November.
<a href=

ESG and its relevance to the public sector

Peter Collins and Sydney Chandler discuss the growing importance of Environmental, Social, and Governance criteria in public procurement.
<a href=

JCT 101: Time and Punishment

Rachel Murray-Smith, Clare Mendelle and Laura Campbell discuss a common Construction scenario regarding the Practical Completion of a project, and the position under the unamended JCT DB 2016.
Icons Court

The importance of due process, communication and fairness in employee conduct investigations – what you need to know.

Julie Bann and James Hughes discuss the importance of fairness in employee conduct investigations, taking a look at the London Borough of Hammersmith and Fulham -v- Mr S Keable case.
<a href=

Becoming More Inclusive: VAT and the Public Procurement (Agreement on Government Procurement) (Thresholds) (Amendment) Regulations 2021

Juli Lau, Natasha Barlow and Beth Edwards examine the recently published Public Procurement Regulations 2021, focussing upon amendments to the thresholds within various procurement regimes.
<a href=

The LADs are Alright

Laura Campbell discusses liquidated damages in construction contracts, focussing upon the long-running Triple Point saga which ended in the Supreme Court this year.
<a href=

Procurement Policy Note 08/21

Juli Lau and Beth Edwards outline Procurement Policy Note 08/21, recently published by the Cabinet office.
Icons Court

Hard Times: Improving Air Quality with Clean Air Zones

Rob Hann and James Goldthorpe examine the introduction of Clean Air Zones to improve air quality across the UK.
<a href=

Autumn Budget Spending Review 2021 – What Public Bodies Need To Know

Rob Hann and James Hughes examine the Autumn Budget Spending Review 2021, looking at what Public Bodies need to know.
<a href=

Net Zero – What’s new for local authorities?

Steve Gummer and Sophie Drysdale look at two major climate publications: the Heat and Buildings Strategy and the Net Zero Strategy.
Icons Hazard

Jumping to conclusions: Final Statements, liquidated damages and material breaches of natural justice

Michael Comba looks at a recent Technology and Construction Court case that provides useful guidance on the JCT’s procedural requirements on disputing Final Statements.
Icons Court

Three times one equals one: Several disputed payment applications amount to a single dispute

Michael Comba considers a case in which the High Court dismissed an employer’s argument that an adjudicator lacked jurisdiction because the referral concerned three separate payment applications and, therefore, comprised three separate disputes.
<a href=

Warm feelings or hot air: the Heat and Buildings Strategy and Heat Networks

This week the government published its Heat and Buildings Strategy (Strategy). This contained vital innovations and essential step changes in terms of how heating is provided, writes Steve Gummer.
<a href=

Procurement reforms: update from Cabinet Office

Rob Hann, Nicola Sumner and Juli Lau assess the Cabinet Office's update on the progress of the government's public procurement reforms.
Icons Court

Bond, Performance Bond. Delivering value for the Public Sector?

Justin Mendelle examines whether public sector clients achieve value for money from the provision of performance bonds.
Icons Hazard

Not so personal messages: R. (on the application of Good Law Project Ltd) v Secretary of State for Health and Social Care and Abingdon Health Plc [2021] EWHC 2595 (TCC)

Nicola Sumner, Juli Lau and Beth Edwards look at The Good Law Project's challenge of the direct award by the Secretary of State for Health and Social Care of three contracts for the production and supply of rapid Covid-19 antibody tests (the “Contracts”).
<a href=

Insolvency – Termination and Beyond

Rachel Murray-Smith and Clare Mendelle consider the potential warning signs of, and the compliant manner for dealing with, contractor insolvency.
Icons Court

Settlement agreements – waiving Personal Injury claims

In the case of Farnham-Oliver v RM Educational Resources LTD, the Queen’s Bench Division of the High Court allowed a Personal Injury claim (“PI claim”) to be pursued by an employee against his former employer despite the parties signing a Settlement Agreement in respect of an Employment Tribunal claim on the same issue. Julie Bann and James Hughes report.
Icons Hazard

Mandatory Vaccination for Care Home Workers in England – Update

Rachel Murray-Smith and Francesca Gallagher look at the detail of the government's guidance on compulsory vaccination for care staff.
<a href=

Make your mind up! Liquidated Damages clause upheld despite Employer’s challenge

In the recent case of Eco World Ballymore (EWB) v Dobler[1] , an Employer took the unusual position of challenging their own entitlement to liquidated damages (LDs) on the ground that the LDs provision constituted an unenforceable penalty clause. Clare Mendelle and James Goldthorpe investigate.
<a href=

Are Collateral Warranties Construction Contracts? Timing is Key.

Clare Mendelle and Anna Sidebottom examine the recently decided case of Toppan v Simply[1], which has provided guidance on when collateral warranties may be considered “construction contracts” under the Housing Grants, Construction and Regeneration Act 1996 and so give the warranty holder the right to adjudicate.
Icons Court

Climate emergency or climate catastrophe?

Rob Hann asks how central & local government departments and councils can work together more effectively to combat the challenges to achieve net zero by 2050.
Icons Court

Big Problems Need Radical Solutions – Time to Play Monopoly with District Heating?

Steve Gummer examines how local authorities might make district heat networks a reality.
<a href=

The Judicial Review and Courts Bill

The Judicial Review and Courts Bill was introduced to the House last week on 21 July 2021. William Rose and Anna Sidebottom discuss the potential impact of the bill.

Mandatory Vaccination for Care Home Workers in England

The Government has announced that people working in care homes in England must be fully vaccinated against Covid-19 from October 2021, unless they have a medical exemption, write Rachel Murray-Smith and Francesca Gallagher.
Icons Court

Transparency in Procurement: Procurement Policy Note (“PPN”) 07/21

Julie Lau, Clare Mendelle and Beth Edwards outline the new regime for publishing procurement notices post-Brexit
Icons Court

When procurement law and contracts for interests in land meet

Colin Ricciardiello provides a case law update examining cases that have examined the overlap between a requirement to procure and a contract for the disposal of an interest in land.
tb w74 h74 crop int a734a5aec8e0dcb7849ee8ebeb84a53d

UK granted data protection adequacy decision

Charlotte Smith summarises the new data protection adequacy decision.

First Impressions on the New Subsidy Control Bill

Last week the Government published its new Subsidy Control Bill. The Bill represents a significant shift in the way in which subsidies are assessed and also provides some clarity about the regime that will replace the EU State aid regime, writes Peter Collins.
Icons Court

Managing new enforcement powers for councils under the Traffic Management Act 2004

Rob Hann considers the recent legislative changes to traffic management in England, including the introduction of Clean Air Zones and widening local authorities enforcement powers for moving traffic offences.
Icons Court

Implementing Net Zero: Taking account of Carbon Reduction Plans in the Procurement of Major Government Contracts

The Government recently published the Procurement Policy Note 06/21. This will require suppliers bidding for major government contracts to provide a Carbon Reduction Plan at the selection stage and commit to achieving Net Zero by 2050, writes Clare Mendelle and James Goldthorpe.
tb w74 h74 crop int a734a5aec8e0dcb7849ee8ebeb84a53d

Public Procurement Update June 2021

On 3 June 2021, the Government issued the National Procurement Policy Statement (NPPS), and the associated Procurement Policy Note (PPN). George Dale explains what each document does.

What a bind: Section 106 planning obligations where there are multiple land interests

Rachel Lee and Christos Paphiti consider whether the case of R (on the application of McLaren) v Woking Borough Council impacts upon local planning authorities (LPAs) ability to properly consider the land interests and parties as regards to performance of specific obligations.
Icons Court

The use of experts only works when everyone plays by the same rules

Colin Ricciardiello looks at the use of expert witnesses in the wake of an important recent decision.
Icons Court

Unlawful Award of Contract

The High Court has ruled that the Minister for the Cabinet Office, Michael Gove, broke the law by giving a contract to a market research company, Public First, who are run by long-time associates of his. Anna Sidebottom, Francesca Gallagher and Clare Mendelle report.
Icons Date

Time after time: extending time for determination of a prior approval application

Rachel Lee and Christos Paphiti examine the time period for determination of Prior Approval (‘PA’) applications and explore how a local authority can extend the time period for determination.
Slide background